Loading...
HomeMy WebLinkAboutBruce McGonigal, Inc. Performance Bond -2000 01 01 ~ THE AMERICAN INSTITUTE OF ARCHITECTS BOND NO. CSB0900108 AM Document A372 Performance Bond Any singulJr reference to Conlractor, Surely, Owner or other parly shall be considered plural where applicable. CONTRACTOR (Name and Address): BRUCE MCGONIGAL, INC. 3940 MOORES STATION RD SANFORD, FL 32773-6523 SURETY (Name and Principal Place of Business): CUMBERLAND SURETY INSURANCE COMPANY 367 WEST SHORT STREET LEXINGTON, KY 40507 OWNER (Name and Address): THE CITY OF WINTER SPRINGS 1126 E. SR 434 WINTER SPRINGS, FL 32708 CONSTRUCTION CONTRACT Date: Amount: $159,400.92 Description (Name and location): GREENSPOINTE RECLAIMED WATER MAIN EXTENSION BOND Date (Not earlier than Construction Contract Date): Amount: $159,400.92 Modific<ltions to this Bond: [J None [] See Page 3 .. CONTRACTOR AS PRINCIPAL Company: BRUCE MeGONI SURETY Company: CUMBERLAND (Corporate Seal) INSURANCE COMPANY (FOR INFORMATION QNL Y-Name, Address and Telephone) AGENT or BROKER: OWNER'S REPRESENTATIVE (Architect, Engineer or POE & BROWN, INC. other party): P.O. BOX 2412 DAYTONA BEACH, FL 32115-2412 (904) 252-9601 AlA DOCUMENT A312 . PERfORMANCE 1l0ND AND l'AYMlNT 1l0ND . DECfMIlER 19114 (I). . AlA (lj) THE AM[fUCAN INSTITUTE 01: AJ.:C1IlHCTS. 1735 NlW YOJ.:K AVE., N.W.. WASHINGTON. D.C. 2000& A312-19M 1 G-S459S-A(1 ) 1 The Contractor and the Surety, jointly and severally, bind themselves, their heirs, executors, administrators, succes- sors and assigns to the Owner for the performance of the Construction Contract, ~vliich is incorporated I~crein by reference. 2 If tl~e Contractor performs the Construction Contract, the Surety and the Contractor shall have no obligation under this Bond, except to participate in conferences as provided in Subparagraph 3.1. 3 If there is no Owner Default, the Surety's obligation under this Bond shall arise after: 3.1 The Owner has notified the Contractor and the Surety at its address described in Paragraph 10 bclo~v that the Owner is considering declaring a Contractor Default and has requested and attempted to arrange a conference with the Contractor and the Surety to be held not later than fifteen days after receipt of such notice to discuss methods of performing the Construction Contract. If the Owner, the Contractor and the Surety agree, the Contrac- tor shall be allowed a reasonable time to perform the Construction Contract, but such an agreement shall not waive the Owner's right, if any, subsequently to declare a Contractor Default; and 3.2 The Owner has declared a Contractor Default and formally terminated the Contractor's right to complete the contract. Such Contractor Default shall not be declared earlier than twenty days after the Contractor and the Surety have received notice as provided in Subparagraph 3.1; and 3.3 The Owner has agreed to pay the Balance of the Contract Price to the Surety in accordance with tl~e terms of tl~e Construction Contract or to a contractor selected to perform the Construction Contract in accordance with the terms o(the contract with tl~e Owner. 4 When the Owner has satisfied the conditions of Para- graph 3, the Surety shall promptlyand at the Surety's expense take one of the following actions: 4.1 Arrange for the Contractor, with consent of the Owner, to perform and complete the Construction Con- tract; or 4.2 Undertake to perform and complete the Construc- tion Contract itself, through its agents or through inde- pendentcontractors; or 4.3 Obtain bids or negotiated proposals from qualified contractors acceptable to the Owner for a contract for performance and completion of the Construction Con- tract, arrange for a contract to be prepared for execution by the Owner and the contractor selected with the Ov`m- er's concurrence, to be secured with performance and payment bonds executed by a qualified surety equivalent to the bonds issued on the Construction Contract, and pay to the Owner the amount of damages as described in Paragraph 6 in excess of the Balance of the Contract Price incurred by the Owner resulting from the Contractor's default; or 4.4 Waive its right to perform and complete, arrange (or completion, or obtain a new contractor and with rea- sonablepromptness under the circumstances: .1 After investigation, determine tic amount for which it may be liable to the Owner and, as soon as practible after the amount is determined, tender payment therefor to the Owner; or .2 Deny liability in whole or in part and notify the Owner citing reasons therefor. 5 If the Surety does not proceed as provided in Paragraph 4 with reasonable promptness, the Surety shall be deemed to be in default on this Bond fifteen days after receipt of an additional written notice from the Owner to the Surety demanding that the Surety perform its obligations under this Bond, and the Owner shall be entitled to enforce any remedy available to the Owner. If the Surety proceeds as provided in Subparagraph 4.4, and the O~vncr refuses the payment tendered orthe Surety has denied liability, in whole or in part, without further notice the Owner shall be entitled to enforce any remedy available to the Owner. G After the Owner has terminated the Contractor's right to complete the Construction Contract, and if the Surety elects to act under Subparagraph 4.1, 4.2, or 4.3 above, then the responsibilities of the Surety to the Owner shall not be greater than those of the Contractor under the Construction Contract, and the responsibilities of the Owner to the Surety shall not be greater than those of the Owner under the Construction Contract. To the limit of the amount of this Bond, but subject to commitment by the Owner of the Balance of the Contract Price to mitigation of costs and damages on the Construction Contract, the Surety js ob- ligatedwithout duplication for: G.1 The responsibilities of the Contractor for correction of defective work and completion of the Construction Contract; 6.2 Additional legal, design professional and delay costs resulting from the Contractor's Default, and resulting from the actions or failure to act of the Surety under Paragraph 4; and G.3 Liquidated damages, or if no liquidated damages arc specified in the Construction Contract, actual damages caused by delayed performance or non-performance of the Contractor. 7 The Surety shall not be liable to tha Owner or others for obligations of the Contractor Lhaf are unrelated to the Construction Contract, and the Ba'ance of the Contract Price shall not be reduced or set off on account of any such unrelated obligations. No right of action shall accrue on this Bond to any person or entity other•than the-Owner or its heirs, executors, administrators or successors. 8 The Surety hereby waives notice of any change, including changes of time,.to the Construction Contract or to related subcontracts, purchase orders and other obligations. 9 Any proceeding, legal or equitable, under this Bond may be instituted in any court of competent jurisdiction in the location in which the work or part of the work is located and shall be instituted within two years after Contractor Default or Ivithin two years after the Contractor ceased working or within two years after the Surety refuses or fails to perform its obligations under this Bond, whichever occurs first. If the provisions of this Paragraph are void or prohibited bylaw, the AIA DOCUAIENT A312 PERFORMANCE DOND AND PAYMENT I30NU • DECEMOER 19114 .CD. • AIA ® A312-i 9134 2 THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVE., N.IN., WASHINGTON, D.C. 2000G '!0,....;;;Z~.~L~~~,,~~f?i.:.,.~": ';:'-;:l."'~:?-:'V;!';;:'~~;Ji::,: ' ,;":;.;:':;~-:;l:'. --;.;-;:~;:, '.C::;'7Zi. _--;;'..::-:-,' :f'~"''- ;?~:"'.' .-'----:::::0:-. '",. - ;'. 'c-.~.'1J_ ~ I111~~~" ..' ,. minimum period of limitation available to sureties as a defense in the jursidiction of the suit shall be applicable. 10 Notice to the Surety, the Owner or the Contractor shall be mailed or delivered to the address shown on the signature page. 11 When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein. The intent is that this Bond shall be construed as a statutory bond and not as a common law bond. 12 DEFINITIONS 12.1 Balance of the Contract Price: The total amount payable by the Owner to the Contractor under the Con- MODIFICATIONS TO THIS BOND ARE AS FOllOWS: ''-''-''~ struction Contract after all proper adjustments have been made, including allowance to the Contractor of any amounts received or to be received by the Owner in settlement of insurance or other claims for damages to which the Contractor is entitled, reduced by all valid and proper payments made to or on behalf of the Contractor under the Construction Contract. 12.2 Construction Contract: The agreement between the Owner and the Contractor identified on the signature page, including all Contract Documents and changes thereto. 12.3 Contractor Default: Failure of the Contractor, which has neither been remedied nor waived, to perform or otherwise to comply with the terms of the Construction Contract. 12.4 Owner Default: Failure of the Owner, which has neither been remedied nor waived, to pay the Contractor as required by the Construction Contract or to perform and complete or comply with the other terms thereof. THE PROVISIONS AND LIMITATIONS OF SECTION 255.05 OR SECTION 713.23 FLORIDA STATUTES, WHICHEVER IS APPLICABLE TO THE CONTRACT ARE INCORPORATED IN THIS BOND BY REFERENCE. ',. (Space is provided below for additional signatures of added parties, other than those i!Ppearing on the cover page.) CONTRACTOR AS PRINCIPAL Company: (Corporate Seal) Signature: Name and Title: Address: "" SURETY Company: (Corporate Seal) Signature: Name and Title: Address: AlA DOCUMENT A312 . PERFORMANCE BOND AND PAYMENT BOND. DECEMBER 1984 ED. . AlA il!I THE AMERICAN INSTITUTE OF ARCHITECTS, 173S NEW YORK AVE., NW., WASHINGTON, D.C. 20006 A312-1984 3