HomeMy WebLinkAboutCarr & Collier INC. Solary Canal STA Improvement Agreement form 2018 02 09 A
SECTION 00500—AGREEMENT FORM
THIS AGREEMENT MADE THIS 10 DAY OF E by u w __— 2018 between the CITY OF
WINTER SPRINGS, a Florida municipal corporation (herein referred to as OWNER) and
Carr& Collier Inc. a Florida corporation authorized and duly licensed
to do business in the State of Florida (herein referred to as CONTRACTOR), as follows:
1. DESCRIPTION OF WORK — CONTRACTOR shall perform the work in accordance with the Contract
Documents for the construction of the Solary Canal STA Improvements.
2. CONTRACT DOCUMENTS — The Contract Documents consist of this Agreement; the Project Manual
including all Technical, General and Supplementary Conditions; the Drawings issued for Bidding; all
Addenda issued prior to and all Change Orders issued after execution of this Agreement; and
Contractor's Bid Submittal. These form the Contract Documents and are incorporated into this Contract
by this reference.
3. ORDER OF PRECEDENCE - In case of any inconsistency in any of the documents bearing on the
Agreement between the OWNER and the CONTRACTOR, the inconsistency shall be resolved by giving
precedence in the following order:
a.Agreement and Addenda
b.CONTRACTOR's Bid Submittal
c.Change Orders
d.Special Conditions
e.General Conditions
f. Drawings
Any inconsistency in the work description shall be clarified by the OWNER and performed by the
CONTRACTOR.
4, AGREEMENT INTERPRETATION - At its discretion, during the course of the work, should any errors,
ambiguities, or discrepancies be found in the Agreement or specifications, the OWNER at its sole
discretion will interpret the intent of the Agreement and work descriptions and the CONTRACTOR
hereby agrees to abide by the OWNER's interpretation and agrees to carry out the work in accordance
with the decision of the OWNER. When the material, article, or equipment is designated by a brand
name and more than one brand name is listed, it will be understood that the work is based on one brand
name only. The CONTRACTOR will be responsible for all coordination necessary to accommodate the
material, article, or equipment being provided without additional cost to the OWNER. A substitute
material, article, or equipment is allowed if it is reasonably equivalent to the brand name specified. The
OWNER has full discretion to decide whether a substitute is reasonably equivalent. CONTRACTOR must
notify the OWNER prior to use of the substitute for a specified brand name and allow the OWNER to
make a determination before CONTRACTOR uses the substitute.
5. CONTRACT TIME - The CONTRACTOR shall begin work within 10 days after the issuance of a written
Notice to Proceed and the Final Completion of all work shall be within 90 calendar days from the date of
the Notice to Proceed. Extensions, if any, are authorized by OWNER, and may only be granted in writing.
14
6. LIQUIDATED DAMAGES - OWNER and CONTRACTOR recognize that time is of the essence of this
Agreement and that OWNER will suffer financial loss if the Work is not substantially complete within the
time specified in Paragraph 5 above, plus any extensions thereof allowed in accordance with the General
Conditions. They also recognize the delays, expense, and difficulties involved in proving in a legal or
arbitration preceding the actual loss suffered by OWNER if the Work is not substantially complete on
time. Accordingly, instead of requiring any such proof, OWNER and CONTRACTOR agree that as
liquidated damages for delay(but not as a penalty) CONTRACTOR shall pay OWNER $250.00 for each day
that expires after the time specified in Paragraph 5 for final completion until the work is finally complete,
and that OWNER has paid to CONTRACTOR the consideration of Ten ($10.00) Dollars as consideration for
this provision.
7. CONTRACT PRICE UNIT PRICE CONTRACT - The OWNER will pay the CONTRACTOR in current funds for
the performance of the work, subject to additions and deductions by Change Order, the Total Contract
Price of $169,074.00 . Payments will be made to the CONTRACTOR for actual quantities
installed on the basis of the Schedule of Unit Prices included as a part of the Bid, which shall be as fully a
part of the Contract as if attached or repeated herein.
8. TERMINATION; DEFAULT BY CONTRACTOR AND OWNER'S REMEDIES,-The OWNER reserves the right to
revoke and terminate this Agreement and rescind all rights and privileges associated with this
Agreement, without penalty, for convenience. Further, the OWNER reserves the right to revoke and
terminate this Agreement in the following circumstances, each of which shall represent a default and
breach of this Agreement:
a. CONTRACTOR defaults in the performance of any material covenant or condition of this
Agreement and does not cure such other default within seven (7) calendar days after written
notice from the OWNER specifying the default complained of, unless, however, the nature of
the default is such that it cannot, in the exercise of reasonable diligence, be remedied within
seven (7) calendar days, in which case the CONTRACTOR shall have such time as is reasonably
necessary to remedy the default, provided the CONTRACTOR promptly takes and diligently
pursues such actions as are necessary therefore; or
b. CONTRACTOR is adjudicated bankrupt or makes any assignment for the benefit of creditors or
CONTRACTOR becomes insolvent, or is unable or unwilling to pay its debts; or
c. CONTRACTOR has acted negligently, as defined by general and applicable law, in performing
the Work hereunder;or
d. CONTRACTOR has committed any act of fraud upon the OWNER; or
e. CONTRACTOR has made a material misrepresentation of fact to the OWNER while performing
its obligations under this Agreement; or
f. CONTRACTOR is experiencing a labor dispute, which threatens to have a substantial, adverse
impact upon performance of this Agreement without prejudice to any other right, or remedy
OWNER may have under this Agreement.
15
Notwithstanding the aforementioned, in the event of a default by CONTRACTOR, the OWNER shall have
the right to exercise any other remedy the OWNER may have by operation of law, without limitation,
and without any further demand or notice. In the event of such termination, OWNER shall be liable only
for the payment of all unpaid charges, determined in accordance with the provisions of this Agreement,
for Work properly performed prior to the effective date of termination.
9. FORCE MAJEURE - Any delay or failure of either party in the performance of its required obligations
hereunder shall be excused if and to the extent caused by acts of God; fire; flood; windstorm; explosion;
riot; war; sabotage; strikes (except involving CONTRACTOR's labor force); extraordinary breakdown of or
damage to OWNER 's affiliates'generating plants,their equipment, or facilities; court injunction or order;
federal and/or state law or regulation; order by any regulatory agency; or cause or causes beyond the
reasonable control of the party affected; provided that prompt notice of such delay is given by such
party to the other and each of the parties hereunto shall be diligent in attempting to remove such cause
or causes. If any circumstance of Force Majeure remains in effect for sixty days, either party may
terminate this Agreement.
10. SEVERABILITY - In the event any portion or part thereof of this Agreement is deemed invalid, against
public policy, void, or otherwise unenforceable by a court of law, the parties, at the sole discretion and
option of the OWNER, shall negotiate an equitable adjustment in the affected provision of this
Agreement. The validity and enforceability of the remaining parts of this Agreement shall otherwise be
fully enforceable.
11. PROGRESS PAYMENTS - OWNER shall make progress payments on account of the contract price to
CONTRACTOR, on the basis of application for payments submitted to the OWNER or OWNER's Project
Manager, by CONTRACTOR as the work progresses, and in accordance with the Contract Documents.
Progress payments may be withheld if:
a. Work is found defective and not remedied;
b. CONTRACTOR does not make prompt and proper payments to SUBCONTRACTORS;
c. CONTRACTOR does not make prompt and proper payments for labor, materials, or equipment
furnished him;
d. Another CONTRACTOR is damaged by an act for which CONTRACTOR is responsible;
e. Claims of liens are filed on the job; or
f. In the opinion of the City of Winter Springs, CONTRACTOR's work is not progressing
satisfactorily
12. FINAL PAYMENT - OWNER shall withhold up to 10% of the Contract Price until 50% completion. After
50% completion, OWNER shall reduce to 5% the amount of retainage withheld from each subsequent
progress payment made to the CONTRACTOR. For purposes of this section, the term "50-percent
completion" shall be the point at which the OWNER has expended 50% of the total cost of the
construction services purchased as identified in the Agreement together with all costs associated with
existing change orders and other additions or modifications to the Agreement. After 50% completion,
the CONTRACTOR may present to the OWNER a payment request for up to one-half of the retainage
16
held by the OWNER. OWNER shall promptly make payment to the CONTRACTOR, unless OWNER has
grounds for withholding the payment of retainage.
OWNER shall make final payment to CONTRACTOR within thirty (30) days after the work is fully and
properly completed, if the contract has been fully and timely performed, but subject to the condition
that final payment shall not be due until CONTRACTOR has delivered to OWNER a complete release of
liens arising out the contract, or receipt releases of lien fully covering all labor, materials and equipment
for which a lien could be filed, or in the alternative a bond satisfactory to OWNER indemnifying him
against such claims.
By making payments OWNER does not waive claims including but not limited to those relating to:
a.Faulty work appearing after substantial completion has been granted;
b.Work that does not comply with the Contract Documents;
c.Outstanding claims of liens; or
d.Failure of CONTRACTOR to comply with any special guarantees required by the Contract Documents
13. DESIGNATION OF PROJECT MANAGER OR ARCHITECT OR LANDSCAPE ARCHITECT: DUTIES AND
AUTHORITY-The duties and authority of the OWNER are as follows:
a. General Administration of Contract. The primary function of the OWNER is to provide the general
administration of the contract. In performance of these duties, Bryant Smith, P.E., or his authorized
representative is the OWNER's Project Manager during the entire period of construction. The
OWNER may change the Project Manager during the term of this contract.
b. Ins ections O inions and Pro ress Re orts. The OWNER shall be kept familiar with the progress
and quality of the work by CONTRACTOR and may make periodic visits to the work site.The OWNER
will not be responsible for the means of construction, or for the sequences, methods, and
procedures used therein, or for the CONTRACTOR's failure to perform the work in accordance with
the Contract Documents.
c. Access to Worksite for Inspections. The OWNER shall be given free access to the worksite at all
times during work preparation and progress. The Project Manager is not obligated to make
exhaustive or continuous on site inspections to perform his duties of checking and reporting on work
progress, and any such inspections shall not waive OWNER's claim regarding defective work by
CONTRACTOR.
d. Interpretation of Contract Documents; Decisions on Djs utes. The OWNER will be the initial
interpreter of the contract document requirements, and make decisions on claims and disputes
between CONTRACTOR and OWNER.
e. Rejection and Stopper a of Work. The OWNER shall have authority to reject work which in its
opinion does not conform to the Contract Documents, and in this connection may stop the work or a
portion thereof,when necessary.
f. Pa ment Certificates. The OWNER will determine the amounts owing to CONTRACTOR as the work
progresses, based on CONTRACTOR's applications and OWNER's inspections and observations, and
17
will issue certificates for progress payments and final payments in accordance with the terms of the
Contract Documents.
14. PROGRESS MEETING — OWNER's Project Manager may hold periodic progress meetings on a monthly
basis, or more frequently if required by the OWNER, during the term of work entered into under this
Agreement. CONTRACTOR's Project Manager and all other appropriate personnel shall attend such
meetings as designated by the OWNER's Project Manager.
15. RESPONSIBILITIES OF CONTRACTOR — CONTRACTOR's duties and rights in connection with the project
herein are as follows:
a. ResPonsibilitv for Supervision and Construction. CONTRACTOR shall be solely responsible for all
construction under this contract, including the techniques, sequences, procedures and means, for
the coordination of all work. CONTRACTOR shall supervise and direct the work, and give it all
attention necessary for such proper supervision and direction.
b. Discioline and Employment. CONTRACTOR shall maintain at all times strict discipline among his
employees, and he agrees not to employ for work on the project any person unfit or without
sufficient skill to perform the job for which he has employed.
c. Furnishing of Labor, Materials,,,etc. CONTRACTOR shall provide and pay for all labor, materials and
equipment, including tools, construction equipment and machinery, utilities, including water,
transportation, and all other facilities and work necessary for the proper completion of work on
the project in accordance with the Contract Documents
d. Payment of Taxes: Procurement of Licenses and Permits. CONTRACTOR shall secure all licenses
and permits necessary for proper completion of the work, paying the fees thereof. CONTRACTOR
warrants that it (and SUBCONTRACTORs or tradesmen, if authorized in the Contract Documents)
hold or will secure all trade or professional licenses required by law for CONTRACTOR to undertake
the contract work.
e. CONTRACTOR will provide written guarantee for work and materials for one (1) calendar year after
acceptance by OWNER.
16. ASSIGNMENT — CONTRACTOR shall not assign or subcontract this Agreement, or any rights or any
monies due or to become due hereunder without the prior,written consent of the OWNER.
a. If upon receiving written approval from OWNER, any part of this Agreement is subcontracted by
CONTRACTOR, CONTRACTOR shall be fully responsible to OWNER for all acts and/or omissions
performed by the subcontractor as if no subcontract had been made.
b. If OWNER determines that any subcontractor is not performing in accordance with this Agreement,
OWNER shall so notify CONTRACTOR who shall take immediate steps to remedy the situation.
18
c. If CONTRACTOR, prior to the commencement of any work subcontracts any part of this Agreement
by the subcontractor, CONTRACTOR shall require the subcontractor to provide OWNER and its
affiliates with insurance coverage as set forth by the OWNER.
17. THIRD PARTY_RIGHTS — Nothing in this Agreement shall be construed to give any rights or benefits to
anyone other than OWNER and CONTRACTOR.
18. PROHIBITION AGAINST CONTINGENT FEES — CONTRACTOR warrants that it has not employed or
retained any company or person, other than a bona fide employee working solely for the CONTRACTOR,
to solicit or secure this Agreement, and that it has not paid or agreed to pay any person, company,
corporation, individual, or firm, other than a bona fide employee working solely for the CONTRACTOR,
any fee, commission, percentage, gift, or other consideration contingent upon or resulting from the
award or making of this Agreement.
19. NO JOINT VENTURE,
— Nothing herein shall be deemed to create a joint venture or principal-agent
relationship between the parties and neither party is authorized to, nor shall either party act toward
third party persons or the public in any manner which would indicate any such relationship with the
other party.
20. INDEMNIFICATION — CONTRACTOR shall indemnify and hold harmless the City, its officers, employees,
and city attorneys (individually and in their official capacity, from liability, losses, damages, and costs,
including, but not limited to, reasonable attorney's fees, to the extent caused by the negligence,
recklessness or intentional wrongful misconduct of CONTRACTOR and persons employed or utilized by
CONTRACTOR in the performance of this Agreement.
The indemnification provided above shall obligate the CONTRACTOR to defend at its own expense or to
provide for such defense, at the option of the OWNER, as the case may be, of any and all claims of
liability and all suits and actions of every name and description that may be brought against the OWNER
or its officers, employees, and city attorneys which may be covered by this indemnification. In all events
the OWNER and its officers, employees, and city attorneys shall be permitted to choose legal counsel of
its sole choice, the fees for which shall be reasonable and subject to and included with this
indemnification provided herein.
21. SAFETY—CONTRACTOR shall be solely and absolutely responsible and assume all liability for the safety
and supervision of its principals, employees, CONTRACTORs, and agents while performing work provided
hereunder.
22. CORPORATE REPRESENTATIONS BY CONTRACTOR — CONTRACTOR hereby represents and warrants to
the OWNER the following:
a. CONTRACTOR is duly registered and licensed to do business in the State of Florida and is in good
standing under the laws of Florida, and is duly qualified and authorized to carry on the functions
and operations set forth in this Agreement.
19
b. The undersigned signatory for CONTRACTOR has the power, authority, and the legal right to
enter into and perform the obligations set forth in this Agreement and all applicable exhibits
thereto, and the execution, delivery, and performance hereof by CONTRACTOR has been duly
authorized by the board of directors and/or president of CONTRACTOR. In support of said
representation, CONTRACTOR agrees to provide a copy to the OWNER of a corporate certificate
of good standing provided by the State of Florida prior to the execution of this Agreement.
C. CONTRACTOR is duly licensed under all local, state and federal laws to provide the work stated in
paragraph 1.0 herein. In support of said representation, CONTRACTOR agrees to provide a copy
of all said licenses to the OWNER prior to the execution of this Agreement.
23. BOND — CONTRACTOR shall supply a materials, performance and payment bond(s) in accordance with
Florida law and to the satisfaction of OWNER, in an amount specified in the Contract Documents.
24. INSURANCE,
- During the term of this Agreement, CONTRACTOR shall be responsible for providing the
types of insurance and limits of liability as set forth below.
a. The CONTRACTOR shall maintain comprehensive general liability insurance in the minimum amount
of $2,000,000 as the combined single limit for each occurrence to protect the CONTRACTOR from
claims of property damages which may arise from any Work performed under this Agreement
whether such Work are performed by the CONTRACTOR or by anyone directly employed by or
contracting with the CONTRACTOR.
b. The CONTRACTOR shall maintain comprehensive automobile liability insurance in the minimum
amount of $1,000,000 combined single limit bodily injury and minimum $1,000,000 property
damage as the combined single limit for each occurrence to protect the CONTRACTOR from claims
for damages for bodily injury, including wrongful death, as well as from claims from property
damage, which may arise from the Ownership, use, or maintenance of owned and non-owned
automobiles, including rented automobiles whether such operations be by the CONTRACTOR or by
anyone directly or indirectly employed by the CONTRACTOR.
c. The CONTRACTOR shall maintain, during the life of this Agreement, adequate Workers'
Compensation Insurance in at least such amounts as are required by law and Employer's Liability
Insurance in the minimum amount of $2,000,000 for all of its employees performing Work for the
OWNER pursuant to this Agreement.
Special Requirements. Current, valid insurance policies meeting the requirements herein identified
shall be maintained during the term of this Agreement. A copy of a current Certificate of Insurance
shall be provided to the OWNER by CONTRACTOR upon the Effective Date of this Contract which
satisfied the insurance requirements of this paragraph 24. Renewal certificates shall be sent to the
OWNER 30 days prior to any expiration date. There shall also be a 30-day advance written
notification to the OWNER in the event of cancellation or modification of any stipulated insurance
coverage. The OWNER shall be an additional named insured on all stipulated insurance policies,as
its interest may appear,from time to time.
20
Independent Associates and Consultants. All independent CONTRACTORS or agents employed by
CONTRACTOR to perform any Work hereunder shall fully comply with the insurance provisions
contained in paragraph 24.
25. MEDIATIONNENUE-The parties agree that should any dispute arise between them regarding the terms
or performance of this Agreement, both parties will participate in mediation. The parties agree to
equally share the cost of the mediator. Should the parties fail to resolve their differences through
mediation, then any cause of action filed hereunder shall be filed in the Circuit or County Court for
Seminole County, Florida.
26. GOVERNING LAW & VENUE - This Agreement is made and shall be interpreted, construed, governed,
and enforced in accordance with the laws of the State of Florida. Venue for any state action or litigation
shall be Seminole County, Florida.Venue for any federal action or litigation shall be Orlando, Florida.
27. ATTORNEYS FEES- Should either party bring an action to enforce any of the terms of this Agreement,
the prevailing party shall be entitled, to the extent permitted by law, to recover from the non-prevailing
party the costs and expenses of such action including, but not limited to, reasonable attorney's fees,
whether at settlement,trial or on appeal.
28. NOTICES - Any notice or approval under this Contract shall be sent, postage prepaid, to the applicable
party at the address shown on the first page of this Contract.
29. WORK IS A PRIVATE UNDERTAKING - With regard to any and all Work performed hereunder, it is
specifically understood and agreed to by and between the parties hereto that the contractual
relationship between the OWNER and CONTRACTOR is such that the CONTRACTOR is an independent
CONTRACTOR and not an agent of the OWNER. The CONTRACTOR, its CONTRACTORS, partners, agents,
and their employees are independent CONTRACTORS and not employees of the OWNER. Nothing in this
Agreement shall be interpreted to establish any relationship other than that of an independent
CONTRACTOR, between the OWNER, on one hand, and the CONTRACTOR, its CONTRACTORS, partners,
employees, or agents,during or after the performance of the Work under this Agreement.
30. DOCUMENTS - Public Records: It is hereby specifically agreed that any record, document, computerized
information and program, audio or video tape, photograph, or other writing of the CONTRACTOR and its
independent CONTRACTORs and associates related, directly or indirectly, to this Agreement, may be
deemed to be a Public Record whether in the possession or control of the OWNER or the CONTRACTOR.
Said record, document, computerized information and program, audio or video tape, photograph, or
other writing of the CONTRACTOR is subject to the provisions of Chapter 119, Florida Statutes, and may
not be destroyed without the specific written approval of the OWNER's City Manager. Upon request by
the OWNER, the CONTRACTOR shall promptly supply copies of said public records to the OWNER. All
books, cards, registers, receipts, documents, and other papers in connection with this Agreement shall at
any and all reasonable times during the normal working hours of the CONTRACTOR be open and freely
exhibited to the OWNER for the purpose of examination and/or audit.
21
The CONTRACTOR acknowledges that the OWNER is a Florida municipal corporation and subject to the
Florida Public Records Law. CONTRACTOR agrees that to the extent any document produced by
CONTRACTOR under this Agreement constitutes a Public Record; CONTRACTOR shall comply with the
Florida Public Records Law.
31. SOVEREIGN IMMUNITY - Notwithstanding any other provision set forth in this Agreement, nothing
contained in this Agreement shall be construed as a waiver of the CITY'S right to sovereign immunity
under Section 768.28, or other limitations imposed on the CITY'S potential liability under state or federal
law. As such, the CITY shall not be liable, under this Agreement for punitive damages or interest for the
period before judgment. Further, the CITY shall not be liable for any claim or judgment, or portion
thereof, to any one person for more than one hundred thousand dollars ($100,000.00), or any claim or
judgment, or portion thereof, which, when totaled with all other claims or judgments paid by the State
or its agencies and subdivisions arising out of the same incident or occurrence, exceeds the sum of two
hundred thousand dollars($200,000.00).
32. HEADINGS- Paragraph headings are for the convenience of the parties only and are not to be construed
as part of this Agreement.
33. INTEGRATION; MODIFICATION - The drafting, execution, and delivery of this Agreement by the Parties
has been induced by no representations, statements, warranties, or agreements other than those
expressed herein. This Agreement embodies the entire understanding of the parties, and there are no
further or other agreements or understandings, written or oral, in effect between the parties relating to
the subject matter hereof unless expressly referred to herein. Modifications of this Agreement shall only
be made in writing signed by both parties.
34. WAIVER AND ELECTION OF REMEDIES - Waiver by either party of any terms, or provision of this
Agreement shall not be considered a waiver of that term, condition, or provision in the future. No
waiver, consent, or modification of any of the provisions of this Agreement shall be binding unless in
writing and signed by a duly authorized representative of each party hereto. This Agreement may be
executed in any number of counterparts, each of which when so executed and delivered shall be
considered an original agreement; but such counterparts shall together constitute but one and the same
instrument.
35. DRAFTING - OWNER and CONTRACTOR each represent that they have both shared equally in drafting
this Agreement and no party shall be favored or disfavored regarding the interpretation of this
Agreement in the event of a dispute between the parties.
36. NOTICE - Any notices required to be given by the terms of this Agreement shall be delivered by hand or
mailed, postage prepaid to:
22
For CONTRACTOR:
Carr& Collier Inc.
1410 Emerson Street
Leesburg, FL 34748
For OWNER:
City of Winter Springs
City Engineer, Public Works Department
1126 East State Road 434,
Winter Springs, FL 32708
Either party may change this notice address by providing the other party writtipp obf ce of he change.
..
Signed, Sealed and Delivered in the presence of:
CONTRACTOR" :
�Y
p
n ' .....� a a mn�Vlr aware o �j.
WitnessJodi Avedisian Name 'oseptf�"i iq i
Pre `dent
P
... Titles""'0 d i noiw.Gu
M. ,'410 Emerson Street
" itnessHolli Martin Business Address
Leesburg, FL 34748
City, State Zip
Date
OWNER:
CITY OF WINTER SPRING `
Witness By. K °Vin L. Smi n
"City Manager
Witness 1126 East State Road 434
Winter Springs, FL 32708
407-327-1800
23
SECTION 00660—NOTICE OF AWARD FORM
TO:
PROJECT NAME:Solar Canal Stormwater Treatment Area Im rovements,
The OWNER has considered the Bid submitted by Carr&Collier Inc. _ for the above
described work in response to the Advertisement for Bids dated December 2017,and Instructions to Bidders.
You are hereby notified that your bid has been accepted and the total amount of the contract award is
$169,074.00
You are required by the Instructions to Bidders to execute the Agreement and certificates of insurance within
ten (10)calendar days from the date of this Notice to you. If you fail to execute said Agreement and to furnish
said certificate of insurance within ten (10) calendar days from the date of this Notice, said OWNER will be
entitled to consider all your rights arising out of the OWNER's acceptance of your BID as abandoned and your
BID BOND shall be forfeited.The OWNER will be entitled to such other rights as may be granted by law,
You are required to return an acknowledged copy of this NOTICE OF AWARD to the OWNER.
Dated this day ofc_� wYV 2018.
OWNER: ' W
BY: '=�_
KeV L. SmitR
Title: City Manager
ACCEPTANCE OF NOTICE
Receipt and acceptanc of the ab OF AWARD is hereby acknowledged by
Jose Ra I this the r - a _ — ..
2018.
GOLL
BY: _. .. _......�. Q4, �P 0 R o
Joseph ,
1
Title: Pr ent SEAL
_.. . r ,
RG,F
29